Combined Synopsis/Solicitation
GAOA Tony Grove Dam Spillway Capacity & Seismic Mitigation, Uinta/Wasatch/Cache National Forest
Department of Agriculture · Forest Service
More open Forest Service contracts
AI summaryThe USDA Forest Service (CSA Northwest 6) is asking small businesses for quotes under request for quotation (RFQ) 1240BH27Q0002 to rebuild parts of Tony Grove Dam on the Uinta-Wasatch-Cache National Forest in Cache County, Utah. Work includes replacing the outlet works and raising the dam crest with added embankment material. The response due date is November 20, 2026, 5:00 PM MST; work runs about June 1, 2027 to October 1, 2027. More in the summary
AI summary Beta
This summary may miss requirements: 2 of 6 attachments weren't read (C04 Attachment 2 - SOI Tony Grove.xlsx, C04 Attachment 5 - DBA WD UT20260105 Cache Co 051826.pdf). Check the attachments on SAM.gov.
The USDA Forest Service (CSA Northwest 6) is asking small businesses for quotes under request for quotation (RFQ) 1240BH27Q0002 to rebuild parts of Tony Grove Dam on the Uinta-Wasatch-Cache National Forest in Cache County, Utah. Work includes replacing the outlet works and raising the dam crest with added embankment material. The response due date is November 20, 2026, 5:00 PM MST; work runs about June 1, 2027 to October 1, 2027.
Who can bid
- Small business concern; this is a total small business set-aside under NAICS 237990 with a $45 million size standard
- Registered in the System for Award Management (SAM) at the time the quote is submitted
- Bid guarantee of 20 percent of the quote, required when the quote is over $150,000, on SF 24 with a power of attorney
How to submit: Email to Contract Specialist Judith Martin at PPS.proposals@usda.gov, with the solicitation name and number as the subject line. What to include is under Full summary below. Check the solicitation's instructions on SAM.gov.
Things to watch (10)
From the version posted Oct 21, 2026.
- Serious: Total small business set-aside. Only small businesses under the $45 million size standard for NAICS 237990 can send quotes.
- Serious: Bid guarantee of 20 percent plus bonds. A bidder needs a surety bid bond and power of attorney with the quote, then performance and payment bonds after award.
- Worth checking: Three to five similar projects within 5 years. Firms need recent projects similar in scope, size and area, so a business without similar heavy civil work may score poorly.
Show all 10Show fewer
- Worth checking: Fixed completion date of October 1, 2027. The whole work must be ready for use by this date, and the schedule is scored within the mandatory period of performance.
- Worth checking: Davis-Bacon wage rates apply. The contract includes construction wage rate requirements and lists a Cache County wage determination, so labor costs must follow those rates.
- Minor: Response due date moved to November 20, 2026. Amendment 0001 changed the response due date from November 2, 2026 at 5:00 PM.
- Minor: The site visit was Oct 15, 2026. Check the notice and its amendments for whether attendance was required, and whether another visit is offered.
- Minor: Questions were due Oct 20, 2026. Check the amendments for the agency's answers.
- Minor: Remote site without utilities. No utilities or fuel storage are available on site, so a bidder must price power, water and fuel logistics as part of the work.
- Minor: Limits on subcontracting. The limitations on subcontracting clause is in the contract, so the prime must do a set share of the work with its own staff.
Read from the notice and 4 attachments. 2 of 6 not read. Show which files.
- C05 Amendment 01 Tony Grove.pdf (read)
- C04 Attachment 3 - Specifications Tony Grove.pdf (read)
- C04 Attachment 1 - Solicitation Tony Grove.pdf (read)
- C04 Attachment 4 - Drawings Tony Grove.pdf (read)
- C04 Attachment 2 - SOI Tony Grove.xlsx: not read (the AI doesn't read this file type yet): open it on SAM.gov
- C04 Attachment 5 - DBA WD UT20260105 Cache Co 051826.pdf: not summarized: open it on SAM.gov
Full summary
What they want
- Reconstruct portions of Tony Grove Dam as shown in the drawings and specifications
- Replace the outlet works and raise the dam crest with added embankment material
- Base item 0001 is the main work; option items are a precast concrete vault restroom (0002) and hot mix asphalt (0003)
- Furnish all labor, materials, equipment, tools and transportation, and price every line in the Schedule of Items
- Meet site rules: no utilities on site, no fuel storage, equipment pressure washed before entry and inspected by the contracting officer's representative
- Complete the whole job ready for use by October 1, 2027, including final cleanup
- Contract type
- Commercial construction quote under FAR Part 12 (request for quotation); base item plus two option line items
- Period of performance
- June 1, 2027 to October 1, 2027 for the base item; options listed June 1, 2027 to November 1, 2027; start work within 10 calendar days after notice to proceed
- Place of performance
- Tony Grove Dam, end of Forest Service Road 20273-Tony Grove Day Use PK, about 25 miles NE of Logan, Utah (Cache County, Logan Ranger District)
- Estimated value
- Price range stated as between $1,000,000 and $5,000,000
- Offers due
- November 20, 2026, 5:00 PM MST
- How to submit
- Email to Contract Specialist Judith Martin at PPS.proposals@usda.gov, with the solicitation name and number as the subject line
- Page limits
- Resumes: 2 pages each; Experience project narratives: 2 pages each
What they'll judge offers on
- Factor 1 Technical and Project Management: (1) technical approach, (2) project management and oversight, (3) performance schedule
- Factor 2 Experience: specialized experience relevant to this project
- Factor 3 Past Performance: recency, relevance and quality of past work
- Price: reasonableness (FAR 12.204) and balanced, consistent unit prices; base and option items are added together
What to include when you submit
- Send Microsoft Word, Microsoft Excel or Adobe PDF files; each part separate, complete and clearly identified
- Number your responses to match the criterion each one answers
- Signed Standard Form 1442 (SF 1442), the solicitation, offer and award form, with blocks 14 to 20c completed
- Schedule of Items (Attachment 2) in Excel or PDF, priced for all items; leaving items out may make the quote nonresponsive
- Acknowledge each amendment in section 19 of the SF 1442 or with signed SF 30 forms
- Scanned, fully executed bid guarantee on Standard Form 24 (SF 24 Bid Bond) with a power of attorney
- Technical approach: equipment, logistics for crew, equipment and materials, crew accommodations if any, major subcontractors and their roles, and biobased products to be used
- Organizational chart or summary from owner level to field level, plus resumes for the project manager, site superintendent, quality control manager and safety officer
- Performance schedule as a time-scaled network diagram, critical path method (CPM) schedule or Gantt chart showing the critical path, with the period in calendar days
- Experience: narratives for at least 3 but not more than 5 projects of similar scope, magnitude and geographic area, in progress or completed within 5 years of the solicitation issue date
- Each project narrative gives name, location, dates, work performed, prime or subcontractor role, contract value, customer, customer contact, and challenges and how they were resolved
- Past performance: list relevant work from the past 5 years with project name, location, description, dollar value, owner and owner contact; for meaningful subcontractors, describe work completed within the past 3 years
After award, you must have
- Performance and payment bonds after award; the winner must sign contract documents and furnish bonds within 10 days after receiving the forms From C04 Attachment 1 - Solicitation Tony Grove.pdf:
…fails to execute all contractual documents or furnish executed bond(s)
Not in the notice text
- Part of the main solicitation was left out of the text read, including the basis for award and the order of importance of the evaluation factors (pages 19 to 20), and the priced Schedule of Items (Attachment 2, a spreadsheet) was attached but not read.
- The Davis-Bacon wage determination UT20260105 for Cache County (Attachment 5) is a scanned file with no readable text, so its wage rates are not stated here.
- How the quotes will be ranked (for example, whether price or non-price factors weigh more) is not stated in the text read.
- Performance and payment bond amounts were not seen.
- Form SF 1442 checkboxes (such as the offer guarantee box) couldn't be read; the solicitation text states the 20 percent bid guarantee requirement.
Eligibility and how to respond
- Set aside for small businesses: only a business that counts as small under this notice's NAICS code can bid as the prime contractor. More open small business set-asides under NAICS 237990
- How to submit, from the AI summary: Email to Contract Specialist Judith Martin at PPS.proposals@usda.gov, with the solicitation name and number as the subject line. Check it in the notice before you send anything.
- Construction contracts over $2,000 pay at least the local Davis-Bacon wage rates, from the wage determination in the solicitation. Price your labor from it: How to price a government contract, and how Davis-Bacon differs from the Service Contract Act.
Notice details
- Posted
- Oct 21, 2026
- Notice type
- Combined Synopsis/Solicitation
- Office
- USDA-FS, CSA Northwest 6, Portland, OR
- Product/service code
- Y1KA · Construction of Dams
- Business type
- Construction & renovation (FedReady's grouping, from NAICS 237990)
- Versions
2 versions have been posted, newest first.
- Oct 21, 2026 · Amendment 0001 (this version)Due Nov 20, 2026 (changed)
- Oct 5, 2026 · Combined Synopsis/SolicitationDue Nov 2, 2026
- Attachments
Past awards and competition
Who has won work like this before, the likely incumbent, and what similar contracts paid, from USAspending.gov.
Before you respond
- How to respond to a solicitation (8 steps)
- How to read a government solicitation
- How to price a government contract
- Set-aside contracts explained
Terms on this notice: Solicitation, Set-aside
Full notice text from SAM.gov
This is a combined synopsis/solicitation for commercial construction prepared in accordance with the format in FAR Part 12. This announcement constitutes the only solicitation; quotes are being requested, and a separate written solicitation will not be issued. Solicitation number 1240BH27Q0002 is issued as a Request for Quotation (RFQ) for the Tony Grove Dam Spillway Capacity & Seismic Mitigation on the Uinta/Wasatch/Cache National Forest. This project consists of reconstructing portions of the Tony Grove Dam as shown in the drawings and described in the specifications. This also includes replacing outlet works and raising the dam crest along with the addition of embankment material. This acquisition is set-aside for small business concerns. The applicable North American Industry Classification System Code is 237990. The small business size standard is $45 Million. This acquisition is a total Small Business set-aside. All responsible sources may submit a quotation which will be considered by the agency. Amendment 01 - Summary: Extend quote due date to November 20, 2026.
Similar open opportunities
- GAOA Grizzly Bear CampgroundThe U.S. Forest Service (Black Hills National Forest) wants a small-business contractor to rebuild Grizzly Bear Campground near Keystone, South Dakota: road work, a new water…
- GAOA Pine Creek Vault Toilet HTNFThe U.S. Forest Service (Humboldt-Toiyabe National Forest) wants quotes only from small businesses to haul and install a government-furnished concrete vault toilet at Pine Creek…
- W9127N27BA005 Foster Spillway Gate Nut Replacements and Re-Tensioning